FAR Part 42 clauses in the FAR overhaul: 9 codified clauses, 0 moved, removed or merged
Every clause the codified FAR places in FAR Part 42 (52.242), with the number under the deviation, the proposed number and the disposition. 9 same number in the deviation text. As at 27 Sep 2026.
Codified in this part
9 clauses| Codified | Title | Under the deviation | Proposed | Disp. |
|---|---|---|---|---|
| 52.242-1 | Notice of Intent To Disallow Costs | 52.242-1 | no proposed rule yet for this part | Kept |
| 52.242-2 | Production Progress Reports | 52.242-2 | no proposed rule yet for this part | Kept |
| 52.242-3 | Penalties for Unallowable Costs | 52.242-3 | no proposed rule yet for this part | Kept |
| 52.242-4 | Certification of Final Indirect Costs | 52.242-4 | no proposed rule yet for this part | Kept |
| 52.242-5 | Payments to Small Business Subcontractors | 52.242-5 | no proposed rule yet for this part | Kept |
| 52.242-13 | Bankruptcy | 52.242-13 | no proposed rule yet for this part | Kept |
| 52.242-14 | Suspension of Work | 52.242-14 | no proposed rule yet for this part | Kept |
| 52.242-15 | Stop-Work Order | 52.242-15 | no proposed rule yet for this part | Kept |
| 52.242-17 | Government Delay of Work | 52.242-17 | no proposed rule yet for this part | Kept |
Which number a given contract carries depends on the deviation its awarding agency has adopted and the date of the solicitation or the modification: a contract carries the deviation number only where its agency adopted that deviation and it applies at that date. The finder shows all three numbers and names the source; it does not decide for you. Confirm which deviation your contracting officer's agency has adopted.